S. 4795

116 S4795 IS: Fighting for Reliable Energy and Ending Doubt for Open Markets Act
 U.S. Senate
 2026-06-16
 text/xml
 EN
 Pursuant to Title 17 Section 105 of the United States Code, this file is not subject to copyright protection and is in the public domain.
 II  119th CONGRESS  2d Session  S. 4795  IN THE SENATE OF THE UNITED STATES   June 16, 2026   Mr. Cotton  (for himself and  Ms. Cortez Masto ) introduced the following bill; which was read twice and referred to the  Committee on Energy and Natural Resources    A BILL
To amend the Energy Act of 2020 to establish enforceable Federal authorization timelines and expedited judicial remedies, to limit Federal actions halting fully permitted projects, and for other purposes.
1.
Short title; table of contents
(a)
Short title
This Act may be cited as the   Fighting for Reliable Energy and Ending Doubt for Open Markets Act   or the   FREEDOM Act  .
(b)
Table of contents
The table of contents for this Act is as follows:
Sec. 1. Short title; table of contents.
Sec. 2. Findings.
TITLE I—Amendment to Energy Act of 2020
Sec. 101. Amendment to Energy Act of 2020.
TITLE II—Mining regulatory clarity
Sec. 201. Hardrock mining mill sites.
TITLE III—Geothermal energy advancement
Sec. 301. Effect of pending civil actions on processing applications relating to geothermal leasing.
Sec. 302. Cost recovery from geothermal leasing, permitting, and inspections.
Sec. 303. Publication of Gold Book for geothermal operations on Federal land.
Sec. 304. Geothermal Ombudsman and Permitting Task Force.
Sec. 305. Geothermal royalties.
Sec. 306. NEPA review.
2.
Findings
Congress finds that—
(1)
energy projects face catastrophic financial losses when Federal agencies revoke permits, fail to adhere to deadlines, or take years to process routine applications for those projects, even in cases in which project sponsors have invested millions of dollars in reliance on Federal approvals;
(2)
the regulatory uncertainty described in paragraph (1)—
(A)
deters critical energy infrastructure investment across all technologies; and
(B)
undermines United States energy security and economic competitiveness; and
(3)
regulatory uncertainty and permitting delays increase the cost of building energy and mineral infrastructure, which—
(A)
raises the cost of living for families in the United States; and
(B)
increases power prices for homes and businesses.
I
Amendment to Energy Act of 2020
101.
Amendment to Energy Act of 2020
(a)
In general
The Energy Act of 2020 (division Z of the Consolidated Appropriations Act, 2021 ( Public Law 116–260 ; 134 Stat. 2418)) is amended by adding at the end the following:
XII
Fighting for reliable energy and ending doubt for open markets
12001.
Definitions
In this title:
(1)
Agency
The term  agency  has the meaning given the term in section 551 of title 5, United States Code.
(2)
Authorization
The term  authorization  means—
(A)
any license, permit, approval, finding, determination, or administrative decision issued by an agency; and
(B)
any interagency consultation that is authorized or required to be conducted under Federal law—
(i)
between or among—
(I)
agencies; and
(II)
in the case of any State that chooses to participate in the environmental review of a covered energy project, 1 or more State agencies; and
(ii)
in order to site, construct, reconstruct, or commence operation of a covered energy project.
(3)
Complex authorization
The term  complex authorization  means an authorization identified as a complex authorization by a lead agency under section 12101(d).
(4)
Covered energy project
The term  covered energy project  means any activity that—
(A)
requires an authorization from an agency;
(B)
is carried out—
(i)
in the United States; or
(ii)
on the outer Continental Shelf (as defined in section 2 of the Outer Continental Shelf Lands Act ( 43 U.S.C. 1331 )); and
(C)
involves the construction of infrastructure—
(i)
to develop, produce, generate, store, transport, or distribute energy;
(ii)
to capture, remove, transport, or store carbon dioxide; or
(iii)
to mine, extract, beneficiate, or process minerals.
(5)
Environmental document
(A)
In general
The term  environmental document  means—
(i)
an environmental assessment;
(ii)
a finding of no significant impact;
(iii)
a notice of intent;
(iv)
an environmental impact statement; and
(v)
a record of decision.
(B)
Inclusions
The term  environmental document  includes any document that is—
(i)
a supplement to a document described in subparagraph (A); or
(ii)
(I)
related to a document described in subparagraph (A); and
(II)
prepared pursuant to a court order.
(6)
Environmental impact statement
The term  environmental impact statement  means a detailed, written statement required under section 102(2)(C) of the National Environmental Policy Act of 1969 ( 42 U.S.C. 4332(2)(C) ).
(7)
Environmental review
The term  environmental review  means any agency procedure or process for—
(A)
applying a categorical exclusion (within the meaning of the National Environmental Policy Act of 1969 ( 42 U.S.C. 4321 et seq. ) (including regulations promulgated pursuant to that Act)); or
(B)
preparing an environmental document under the National Environmental Policy Act of 1969 ( 42 U.S.C. 4321 et seq. ).
(8)
Lead agency
The term  lead agency , with respect to a covered energy project, means the agency with principal responsibility for environmental review of the covered energy project under the National Environmental Policy Act of 1969 ( 42 U.S.C. 4321 et seq. ) (including regulations promulgated pursuant to that Act).
(9)
Project sponsor
The term  project sponsor  means a private, public, or public-private entity seeking an authorization for a covered energy project.
(10)
Reviewing court
The term  reviewing court  means the court of competent jurisdiction in which a petition under subtitle B is filed.
(11)
Routine authorization
The term  routine authorization  means any authorization that is not a complex authorization.
A
Authorization timelines
12101.
Notices of initiation; project schedules
(a)
Notices of initiation for covered energy projects
(1)
In general
A project sponsor shall submit a notice of initiation for a covered energy project proposed to be carried out by the project sponsor to the head of each agency from which 1 or more authorizations are anticipated to be required to carry out the covered energy project.
(2)
Contents
A notice of initiation under this subsection shall include—
(A)
a statement describing the purposes and objectives of the proposed covered energy project;
(B)
a concise description of the proposed covered energy project, including—
(i)
the general location of the proposed covered energy project; and
(ii)
a summary of geospatial information, if available, illustrating—
(I)
the proposed project area; and
(II)
the locations of known environmental, cultural, and historic resources, if any; and
(C)
a statement identifying all Federal financing, environmental reviews, and authorizations anticipated to be required to carry out the proposed covered energy project.
(b)
Determination of completeness
(1)
In general
Not later than 30 days after the date of receipt of a notice of initiation under subsection (a), the applicable lead agency shall determine whether the notice is complete in accordance with paragraph (2).
(2)
Completeness
A notice of initiation shall be considered to be complete under paragraph (1) if the lead agency determines that the notice meets the requirements described in subsection (a)(2).
(3)
Statement
(A)
In general
A lead agency, on making a determination under paragraph (1) that—
(i)
a notice of initiation is complete, shall provide to the project sponsor a statement of the determination; or
(ii)
a notice of initiation is incomplete, shall provide to the project sponsor a deficiency statement identifying the information required for the notice to be considered complete.
(B)
Failure to act
If a lead agency fails to issue a statement under this paragraph by the applicable deadline described in paragraph (1), the applicable notice of initiation shall be deemed to be complete.
(4)
Effect of deficiency
(A)
Response by project sponsor
If a lead agency issues a deficiency statement under paragraph (3)(A)(ii), the project sponsor may—
(i)
submit to the lead agency a revised notice containing the information identified in the deficiency statement not later than 90 days after the date on which the deficiency statement is issued; or
(ii)
request an extension of time to prepare such a revised notice.
(B)
Extension
On receipt of a request for an extension under subparagraph (A)(ii), a lead agency shall grant the applicable project sponsor an extension of the applicable deadline under subparagraph (A)(i) for a period of not more than 90 days.
(c)
Project schedule
Not later than 30 days after the date on which a notice of initiation for a proposed covered energy project is determined or deemed to be complete under subsection (b), the applicable lead agency shall publish a schedule for the covered energy project that—
(1)
(A)
lists each authorization known, or reasonably anticipated, to be required for the covered energy project; and
(B)
identifies each such authorization as a routine authorization or a complex authorization, in accordance with subsection (d);
(2)
identifies each Federal, State, Tribal, and local agency that has been designated as a cooperating agency for the covered energy project in accordance with the National Environmental Policy Act of 1969 ( 42 U.S.C. 4321 et seq. ), if applicable; and
(3)
establishes for the covered energy project—
(A)
interim milestones; and
(B)
final decision dates in accordance with section 12102.
(d)
Identification of authorizations
(1)
In general
For each authorization required for a covered energy project for which a schedule is published under subsection (c), the lead agency shall identify the authorization as—
(A)
a complex authorization if the authorization is—
(i)
described in paragraph (2); or
(ii)
designated by the lead agency pursuant to paragraph (3)(A); or
(B)
a routine authorization if the authorization is not identified as a complex authorization under subparagraph (A).
(2)
Description of complex authorizations
A complex authorization referred to in paragraph (1)(A)(i) is an authorization that—
(A)
requires the issuance of an authorization or certification of public convenience and necessity under section 3(e) or 7(c) of the Natural Gas Act ( 15 U.S.C. 717b(e) , 717f(c));
(B)
requires the issuance of a license or permit under section 4(e) or 216 of the Federal Power Act ( 16 U.S.C. 797(e) , 824p);
(C)
requires the issuance of a lease, easement, right-of-way, or other authorization under section 5 or 8(p) of the Outer Continental Shelf Lands Act ( 43 U.S.C. 1334 , 1337(p));
(D)
requires the preparation of an environmental assessment or environmental impact statement;
(E)
requires formal consultation under section 7 of the Endangered Species Act of 1973 ( 16 U.S.C. 1536 ) or results in the issuance of a biological opinion;
(F)
requires consultation under section 306108 of title 54, United States Code, that the lead agency anticipates will take longer than 90 days;
(G)
grants a new or expanded right-of-way, easement, lease, or comparable real property interest exceeding 20 acres of Federal property; or
(H)
requires an individual permit under section 404 of the Federal Water Pollution Control Act ( 33 U.S.C. 1344 ) or an individual water quality certification under section 401 of that Act ( 33 U.S.C. 1341 ).
(3)
Designations by lead agency
(A)
In general
A lead agency may designate an authorization as a complex authorization based on a written, reasoned determination of the lead agency that identifies factors that—
(i)
are specific to the applicable covered energy project; and
(ii)
are not described in subparagraphs (A) through (H) of paragraph (2).
(B)
Judicial review
The designation by a lead agency of a complex authorization pursuant to subparagraph (A) shall be subject to judicial review by the applicable reviewing court under subtitle B.
12102.
Authorization deadlines
(a)
Definition of completed notice date
In this section, the term  completed notice date , with respect to a covered energy project, means the date on which the notice of initiation under section 12101(a) for the covered energy project is—
(1)
determined to be complete under section 12101(b)(1); or
(2)
deemed to be complete under section 12101(b)(3)(B).
(b)
Deadlines
Except as provided in subsections (c) and (d), each agency that receives from a project sponsor a notice of initiation under section 12101(a) for a covered energy project shall issue a final decision regarding each authorization for the covered energy project that is under the jurisdiction of the agency not later than—
(1)
the date that is 90 days after the completed notice date of the covered energy project, if the authorization is a routine authorization; and
(2)
the date that is 1 year after the completed notice date of the covered energy project, if the authorization is a complex authorization.
(c)
Extension for environmental impact statements
Notwithstanding subsection (b), if the lead agency publishes a notice of intent to prepare an environmental impact statement for a covered energy project after the completed notice date of the covered energy project, the deadline for completion of the environmental impact statement, and for each final decision regarding an authorization for the covered energy project that depends on completion of that environmental impact statement, shall be the date that is 2 years after the completed notice date.
(d)
Earlier deadlines under other Federal law
If another provision of Federal law requires an agency to issue a final decision regarding an authorization by a date that is earlier than the applicable deadline under subsection (b) or (c), the agency shall issue the final decision not later than that earlier date.
(e)
Failure To meet deadline
(1)
In general
Except as provided in paragraph (2), the failure by an agency to adhere to a deadline under this section or a milestone under section 12101(c)(3)(A) shall be—
(A)
considered to be an agency action unlawfully withheld or unreasonably delayed under section 706(1) of title 5, United States Code; and
(B)
subject to review by a reviewing court under subtitle B.
(2)
Exceptions
The failure by an agency to adhere to a deadline under this section or a milestone under section 12101(c)(3)(A) shall not be considered to be an agency action unlawfully withheld or unreasonably delayed under section 706(1) of title 5, United States Code, if—
(A)
the project sponsor and the agency agree to a different deadline or milestone; or
(B)
a reviewing court determines that—
(i)
a natural disaster reasonably impaired the ability of the agency to adhere to the deadline or milestone; or
(ii)
a national emergency or extraordinary circumstance exists for which the only available remedy is to delay the deadline or milestone.
12103.
Reviewing court-approved contractors
(a)
Definition of eligible project
In this section, the term  eligible project  means a covered energy project with respect to which a reviewing court has—
(1)
found that an agency has failed to adhere to a deadline or milestone; and
(2)
issued an order described in section 12204(b)(2)(C).
(b)
Project sponsor request
(1)
In general
On receipt of a request from the project sponsor of an eligible project, a reviewing court may authorize the project sponsor to retain a qualified contractor to complete any necessary analysis or documentation, in accordance with this subsection.
(2)
Inclusions
A project sponsor request under paragraph (1) shall include—
(A)
identifying information for the contractor proposed to be hired by the project sponsor; and
(B)
the qualifications of that contractor, including—
(i)
relevant professional credentials;
(ii)
prior experience with environmental reviews; and
(iii)
disclosure of any potential conflicts of interest that are material to the work to be performed, including—
(I)
any financial interest in the outcome of the applicable eligible project;
(II)
any contingent or success-based compensation arrangement;
(III)
any prior engagement with the project sponsor;
(IV)
any equity ownership with a 10-percent or greater interest;
(V)
any contractual relationship, during the 2-year period preceding the date of the request, between the contractor and an engineering, procurement, or construction firm acting as a prime contractor for the eligible project; and
(VI)
any current engagement relating to the eligible project.
(3)
Approval
(A)
In general
Not later than 30 days after the date of receipt of a request of a project sponsor under this subsection, the reviewing court shall approve or reject the proposed contractor that is the subject of the request based on—
(i)
the demonstrated technical competence of the contractor for the required analyses;
(ii)
the absence of disqualifying conflicts of interest;
(iii)
the agreement of the contractor—
(I)
to operate under the technical guidance of the applicable agency;
(II)
to maintain independence in professional judgment; and
(III)
to proceed under the direction of the reviewing court if the agency fails to provide technical guidance or timely review by an applicable deadline under subsection (g); and
(iv)
a determination by the reviewing court regarding whether the contractor meets the qualifications described in subparagraph (B).
(B)
Qualifications
The qualifications referred to in subparagraph (A)(iv), with respect to a contractor, are that the contractor—
(i)
holds a recognized professional license or certification applicable to the work, or has demonstrably comparable expertise;
(ii)
has demonstrated experience completing similar analyses for agencies during the preceding 5-year period;
(iii)
is not debarred or suspended from Federal contracting; and
(iv)
maintains professional liability insurance of not less than $1,000,000.
(C)
Form of approval
The approval of a reviewing court under this paragraph may include any conditions or limitations necessary to ensure compliance with applicable law.
(c)
Standards and obligations
(1)
In general
A contractor approved by a reviewing court under subsection (b) shall—
(A)
follow applicable laws (including regulations) and technical standards relevant to the analyses performed by the contractor;
(B)
certify under penalty of perjury that the work product of the contractor—
(i)
is factually accurate, to the best of the knowledge and belief of the contractor;
(ii)
was prepared using generally accepted professional methods; and
(iii)
complies with applicable professional standards and practices;
(C)
maintain professional independence from the applicable project sponsor in all technical determinations and analyses;
(D)
remain subject to applicable professional liability and ethical standards; and
(E)
execute a sworn conflict of interest and relationship disclosure, as described in subsection (b)(2)(B)(iii), and maintain a log of material communications with the project sponsor, which shall be made available to the reviewing court and any applicable agency on request.
(2)
Status of work product
All work product of a contractor approved under this section shall be—
(A)
deemed to be received by the applicable agency on submission by the contractor; and
(B)
included in the administrative record relating to each relevant authorization.
(d)
Payment
(1)
In general
All reasonable costs of a contractor approved by a reviewing court under this section, including the costs of studies, modeling, and coordination, shall be paid—
(A)
by the relevant lead agency from amounts in the Permitting Performance Fund established by section 12104(a); and
(B)
at rates not higher than comparable rates on the Federal Supply Schedule of the General Services Administration, or as otherwise determined to be reasonable by the reviewing court.
(2)
Advances
(A)
In general
A project sponsor may advance to a contractor approved under this section payment for any costs described in paragraph (1).
(B)
Reimbursement
The relevant lead agency shall reimburse a project sponsor that makes an advance payment under subparagraph (A) not later than 30 days after the date on which the project sponsor submits to the lead agency an invoice relating to the advance payment.
(e)
Scope of work
A contractor approved by a reviewing court under this section shall prepare only the documentation necessary to complete the relevant administrative record.
(f)
Production of government information
(1)
In general
On a motion of the project sponsor or a contractor approved by a reviewing court under this section, the reviewing court may order any agency, or any State or local agency, identified as a cooperating agency in the project schedule under section 12101(c)(2), to produce, by a date certain, any document, data, or expert input necessary to complete the relevant administrative record.
(2)
No tolling
A failure by an agency to produce a document, data, or input by the applicable date under paragraph (1) shall not toll any deadline under this title.
(g)
Deadlines for contractor work
A reviewing court shall establish deadlines for deliverables of a contractor approved by the reviewing court under this section, subject to the condition that such a deadline shall not exceed—
(1)
120 days for a complex authorization not requiring an environmental impact statement; and
(2)
240 days for a complex authorization requiring an environmental impact statement.
(h)
Agency decisions on contractor-Prepared record
(1)
Agency action
Not later than 30 days after the date on which a contractor approved by a reviewing court under this section submits to an applicable agency the completed documentation prepared by the contractor, the agency shall—
(A)
independently evaluate the documentation, take responsibility for the contents, and issue a final decision regarding the applicable authorization, based on the documentation; or
(B)
identify, including a citation to the applicable law or regulation, any specific legal deficiency in the documentation that requires correction, subject to paragraph (2)(C).
(2)
Deficiencies
(A)
In general
If an agency identifies a deficiency under paragraph (1)(B), the affected contractor shall correct the deficiency not later than 90 days after the date on which the identification occurs.
(B)
Action by agency
Not later than 14 days after the date of receipt of corrected documentation under subparagraph (A), an agency shall issue a final decision regarding the applicable authorization.
(C)
Single identification
An agency may identify deficiencies under paragraph (1)(B) on only 1 occasion, unless the applicable reviewing court approves another identification for good cause based on a legal requirement that was not in effect at the time of the initial identification of deficiencies.
(3)
Limitation
An agency may not reject any documentation prepared by a contractor approved by a reviewing court under this section based on a policy disagreement or any other discretionary factor if the documentation satisfies all applicable legal requirements.
12104.
Permitting Performance Fund
(a)
Establishment
There is established in the Treasury a fund, to be known as the  Permitting Performance Fund  (referred to in this section as the  Fund ), consisting of such amounts as are appropriated to the Fund pursuant to subsection (c).
(b)
Use of funds
Amounts in the Fund shall be available, without further appropriation, to pay the costs of any contractor approved by a reviewing court under section 12103(b).
(c)
Authorization of appropriations
There are authorized to be appropriated to the Fund—
(1)
$50,000,000 for the initial capitalization of the Fund; and
(2)
thereafter, such sums as are necessary to carry out this section.
12105.
Effective date
(a)
In general
This subtitle shall apply to any notice of initiation submitted under section 12101(a) for a covered energy project on or after the date that is 90 days after the date of enactment of this title.
(b)
Pending projects
For a covered energy project the notice of initiation for which is pending on the effective date described in subsection (a)—
(1)
this subtitle shall apply beginning on the date that is 120 days after the date of enactment of this title; and
(2)
as applicable, the completed notice date (as defined in section 12102(a)) shall be deemed to be the date that is 120 days after that date of enactment.
B
Judicial review
12201.
Causes of action
(a)
In general
Subject to subsection (b), a project sponsor of a covered energy project may file a petition in accordance with section 12202 for judicial review of—
(1)
a final agency action relating to the covered energy project;
(2)
an alleged failure by an agency—
(A)
to act on the covered energy project, including through unlawful withholding or unreasonable delay; or
(B)
to adhere to—
(i)
a milestone established for the covered energy project under section 12101(c)(3)(A); or
(ii)
a deadline applicable to the covered energy project under section 12102; or
(3)
an order, directive, suspension, revocation, or other action described in section 12301(b) of an agency relating to the covered energy project.
(b)
Single petition rule
(1)
In general
A project sponsor may file only 1 petition under this subtitle with respect to any single cause of action described in subsection (a).
(2)
Multiple grounds
A project sponsor may file a single petition under this subtitle seeking multiple grounds for relief.
(c)
Relief sought
A petition under this subtitle may seek 1 or more of the following:
(1)
Review of an order, directive, or action described in section 12301(b).
(2)
A court order compelling agency action or other relief for an unreasonable delay in the authorization process, in accordance with this title.
(3)
Review of the designation of an authorization as a complex authorization pursuant to section 12101(d)(3).
(d)
Intervention
(1)
In general
Any person that would have standing under article III of the Constitution of the United States to challenge or defend the applicable agency action may move to intervene in a cause of action under this subtitle.
(2)
Ruling
The reviewing court shall rule expeditiously on any motion to intervene under paragraph (1).
(e)
Savings clause
Nothing in this title waives, limits, constitutes an election of remedies against, or establishes an exclusive statutory remedy that precludes, any claim by a project sponsor or other entity for just compensation under the Fifth Amendment to the Constitution of the United States.
12202.
Petition requirements
(a)
Contents
(1)
Requirements
A petition under this subtitle shall contain an affidavit, together with supporting documentation described in paragraph (2), demonstrating the grounds for the petition as follows:
(A)
Actions relating to fully permitted projects
A petition alleging that an agency violated section 12301 with respect to a covered energy project shall demonstrate that—
(i)
the agency issued an order or directive, revoked a permit or authorization, or carried out any other action to halt, delay, or otherwise cancel a previously authorized activity in violation of section 12301; and
(ii)
the project sponsor has suffered or will suffer harm as a direct result of the action described in clause (i).
(B)
Unreasonable delays
A petition alleging unreasonable delay by an agency with respect to a covered energy project shall demonstrate that—
(i)
the petitioner is a project sponsor that has submitted a notice of initiation under section 12101(a) for the covered energy project;
(ii)
the notice was, on such date as the project sponsor shall specify—
(I)
determined to be complete under section 12101(b)(1); or
(II)
deemed to be complete under section 12101(b)(3)(B);
(iii)
the applicable deadline for a final decision relating to an authorization for the covered energy project under section 12102 has lapsed without the agency issuing the final decision; and
(iv)
the petitioner has suffered or will suffer harm as a result of the lapse described in clause (iii).
(C)
Designations as complex
A petition seeking review of the designation of an authorization as a complex authorization shall demonstrate that the written, reasoned determination by the applicable lead agency fails to identify project-specific factors that justify the designation, in accordance with section 12101(d)(3).
(2)
Documents and other information
(A)
In general
A petition under this subtitle shall include, as applicable to each claim asserted in the petition—
(i)
all relevant agency correspondence (including any application for an authorization), deficiency notices, and determinations relating to a notice of initiation or project schedule for the applicable covered energy project, if any;
(ii)
a copy of each final agency action, authorization, record of decision, environmental document, or order that is the subject of the petition; and
(iii)
identification, to the maximum extent practicable, of any records similar to the records described in this subparagraph that are unavailable to the petitioner and the reasons for the unavailability.
(B)
Additional information
A petition for judicial review under this subtitle may include other available relevant documents, such as expert reports, economic analyses, or affidavits from personnel, relating to—
(i)
the applicable covered energy project;
(ii)
action or inaction by an applicable agency; or
(iii)
harm suffered by the petitioner.
(b)
Naming of respondents
(1)
In general
In a petition under this subtitle challenging the schedule for a covered energy project under section 12101(c), or the designation of an authorization as a complex authorization under section 12101(d)(3), the head of the applicable lead agency shall be named as the respondent.
(2)
Other causes of action
In a petition under this subtitle relating to a cause of action not described in paragraph (1), the head of the agency that carried out the applicable final agency action, issued the applicable order or directive, or is alleged to have unlawfully withheld or unreasonably delayed action shall be named as the respondent.
(c)
Filing dates
(1)
Final agency actions
A petition under this subtitle for a cause of action described in section 12201(a)(1) shall be filed not later than 60 days after the date on which the applicable agency action becomes final.
(2)
Failures to act
A petition under this subtitle for a cause of action described in section 12201(a)(2) may be filed beginning on the date that is 30 days after the date of the applicable missed deadline or milestone.
(3)
Actions relating to fully permitted projects
A petition under this subtitle for a cause of action described in section 12201(a)(3) shall be filed not later than 30 days after the date on which the applicable order, directive, suspension, revocation, or other action of an agency is issued or carried out.
(d)
Service
The petitioner shall serve a petition under this subtitle on—
(1)
the Attorney General of the United States;
(2)
the head of the lead agency with respect to the covered energy project that is the subject of the petition; and
(3)
each cooperating agency identified under section 12101(c)(2) in the project schedule for the covered energy project that is the subject of the petition.
12203.
Review by reviewing courts
(a)
Standard of review
(1)
In general
A reviewing court shall conduct the review of, and reach a decision regarding, a petition under this subtitle in accordance with  chapter 7  of title 5, United States Code.
(2)
Administrative record
(A)
In general
Judicial review of a petition under this subtitle shall be based on an administrative record compiled and certified by the head of the agency named in the petition as the respondent under section 12202(b).
(B)
Multiple respondents
If multiple agency heads are named in a petition as respondents under section 12202(b)—
(i)
each agency head shall compile and certify the portions of the record within the custody of that agency; and
(ii)
the lead agency, or such other agency as the reviewing court may require, shall assemble a consolidated record.
(C)
Failures to act
The administrative record relating to a petition under this subtitle for a cause of action described in section 12201(a)(2) shall include, as applicable—
(i)
the notice of initiation submitted under section 12101(a);
(ii)
any completeness or deficiency designation of that notice under section 12101(b);
(iii)
the project schedule published under section 12101(c); and
(iv)
any other materials the reviewing court determines to be necessary to resolve the petition.
(b)
Representation of respondents
A respondent named under section 12202(b) shall be represented in accordance with section 518(a) of title 28, United States Code.
(c)
Additional submissions
In addition to the documents and information required under section 12202(a)(2), a petitioner shall submit to the reviewing court, in accordance with a schedule established by the reviewing court, such other records and documents as are reasonable and necessary for determination of the appropriate remedy.
(d)
Discovery and record development
(1)
In general
There shall be no discovery in a proceeding relating to a petition under this subtitle other than such discovery as may be ordered by the reviewing court, as the reviewing court determines to be reasonable and necessary to determine the appropriate remedy.
(2)
Information, testimony, and documents
The reviewing court may require the submission of such information, the testimony of such persons, and the production of such documents as the reviewing court determines to be reasonable and necessary for purposes of this subsection.
12204.
Expedited procedure; relief; appeals
(a)
Expedited procedure
A reviewing court shall—
(1)
establish an expedited schedule for briefing and disposition relating to a petition under this subtitle; and
(2)
absent extraordinary circumstances, issue a decision with respect to a petition under this subtitle as expeditiously as practicable.
(b)
Available relief
(1)
In general
On a finding by a reviewing court that a petitioner is entitled to relief under this subtitle, the reviewing court shall grant such legal, equitable, and administrative relief as the reviewing court determines to be appropriate to effectuate the purposes of this title in accordance with paragraph (2).
(2)
Actions by reviewing court
A reviewing court that makes a finding described in paragraph (1) shall, as applicable—
(A)
hold unlawful and set aside any final agency action found to be arbitrary, capricious, an abuse of discretion, or otherwise not in accordance with law;
(B)
remand each applicable matter to the appropriate agency for further action in accordance with the direction of the reviewing court, together with a schedule and deadline for completion of those actions, which deadline shall not exceed—
(i)
180 days after the date on which the judgment is issued; or
(ii)
such longer period to which the project sponsor may agree; and
(C)
in any case involving unlawful withholding or unreasonable delay, issue an order that—
(i)
compels the appropriate agency to act;
(ii)
specifies the date by which each discrete action of the agency shall be completed in order to finalize the agency review and issue a final agency decision; and
(iii)
retains the jurisdiction of the reviewing court to ensure compliance with the order.
(c)
Appeals
Any party aggrieved by a final judgment of a reviewing court under this subtitle, other than a judgment of a United States court of appeals, may obtain review in the United States court of appeals of competent jurisdiction under  chapter 83  of title 28, United States Code, subject to the condition that a notice of appeal shall be filed not later than 60 days after the date of entry of the judgment.
C
Fully permitted projects
12301.
Treatment of fully permitted projects
(a)
Definition of fully permitted project
In this section, the term  fully permitted project  means a covered energy project that has received a substantial majority of the authorizations required for the covered energy project.
(b)
Prohibition
No agency or Federal official shall issue any order or directive terminating the construction or operation of a fully permitted project, revoke any permit or authorization for a fully permitted project, or take any other action to halt, suspend, delay, or terminate an authorized activity carried out to support a fully permitted project unless—
(1)
there exists—
(A)
a clear, immediate, and substantiated harm for which the Federal order, directive, or action is required to prevent, mitigate, or repair; and
(B)
no other viable alternative that would allow a previously authorized activity, such as construction, to continue; or
(2)
(A)
an applicable authorization is illegal under applicable Federal law; and
(B)
the Federal order, directive, or action is the only available remedy to address that illegality.
(c)
Limitation on petitions
(1)
In general
No agency may petition a court for voluntary remand of an authorization for a fully permitted project that has received a record of decision unless the project sponsor consents to the petition.
(2)
In-camera review
As necessary, a court may review a petition submitted under this subsection in camera.
(d)
Effective date
This section shall apply to any order, directive, suspension, revocation, or other agency action described in subsection (b) that is issued or carried out on or after the date of enactment of this title.
 .
(b)
Clerical amendment
The table of contents contained in section 101(b) of the Energy Act of 2020 ( Public Law 116–260 ; 134 Stat. 2418) is amended by adding at the end the following:
TITLE XII—Fighting for reliable energy and ending doubt for open markets
Sec. 12001. Definitions.
Subtitle A—Authorization timelines
Sec. 12101. Notices of initiation; project schedules.
Sec. 12102. Authorization deadlines.
Sec. 12103. Reviewing court-approved contractors.
Sec. 12104. Permitting Performance Fund.
Sec. 12105. Effective date.
Subtitle B—Judicial review
Sec. 12201. Causes of action.
Sec. 12202. Petition requirements.
Sec. 12203. Review by reviewing courts.
Sec. 12204. Expedited procedure; relief; appeals.
Subtitle C—Fully permitted projects
Sec. 12301. Treatment of fully permitted projects.
  .
II
Mining regulatory clarity
201.
Hardrock mining mill sites
(a)
Multiple mill sites
Section 2337 of the Revised Statutes ( 30 U.S.C. 42 ) is amended by adding at the end the following:
(c)
Additional mill sites
(1)
Definitions
In this subsection:
(A)
Mill site
The term  mill site  means a location of public land that is reasonably necessary for waste rock or tailings disposal or other operations reasonably incident to mineral development on, or production from, land included in a plan of operations.
(B)
Operations; operator
The terms  operations  and  operator  have the meanings given those terms in section 3809.5 of title 43, Code of Federal Regulations (as in effect on the date of enactment of this subsection).
(C)
Plan of operations
The term  plan of operations  means a plan of operations that an operator is required to submit, and the Secretary of the Interior or the Secretary of Agriculture, as applicable, is required to approve, before the operator may begin operations, in accordance with, as applicable—
(i)
subpart 3809 of title 43, Code of Federal Regulations (or successor regulations establishing application and approval requirements); and
(ii)
part 228 of title 36, Code of Federal Regulations (or successor regulations establishing application and approval requirements).
(D)
Public land
The term  public land  means land owned by the United States that is open to location under sections 2319 through 2344 of the Revised Statutes ( 30 U.S.C. 22 et seq. ), including—
(i)
land that is mineral-in-character (as defined in section 3830.5 of title 43, Code of Federal Regulations (as in effect on the date of enactment of this subsection));
(ii)
nonmineral land (as defined in section 3830.5 of title 43, Code of Federal Regulations (as in effect on the date of enactment of this subsection)); and
(iii)
land the mineral character of which has not been determined.
(2)
Authorization
Notwithstanding subsections (a) and (b), if public land is needed by the proprietor of a lode or placer claim for operations in connection with any lode or placer claim within the proposed plan of operations, the proprietor may—
(A)
locate and include within the plan of operations as many mill site claims under this subsection as are reasonably necessary for its operations; and
(B)
use or occupy public land in accordance with an approved plan of operations.
(3)
Mill sites convey no mineral rights
A mill site under this subsection does not convey mineral rights to the locator.
(4)
Size of mill sites
A location of a single mill site under this subsection shall not exceed 5 acres.
(5)
Mill site and lode or placer claims on same tracts of public land
A mill site may be located under this subsection on a tract of public land on which the claimant or operator maintains a previously located lode or placer claim.
(6)
Effect on mining claims
The location of a mill site under this subsection shall not affect the validity of any lode or placer claim, or any rights associated with such a claim.
(7)
Patenting
A mill site under this section shall not be eligible for patenting.
(8)
Savings provisions
Nothing in this subsection—
(A)
diminishes any right (including a right of entry, use, or occupancy) of a claimant;
(B)
creates or increases any right (including a right of exploration, entry, use, or occupancy) of a claimant on land that is not open to location under the general mining laws;
(C)
modifies any provision of law or any prior administrative action withdrawing land from location or entry;
(D)
limits the right of the Federal Government to regulate mining and mining-related activities (including requiring claim validity examinations to establish the discovery of a valuable mineral deposit) in areas withdrawn from mining, including under—
(i)
the general mining laws;
(ii)
the Federal Land Policy and Management Act of 1976 ( 43 U.S.C. 1701 et seq. );
(iii)
the Wilderness Act ( 16 U.S.C. 1131 et seq. );
(iv)
sections 100731 through 100737 of title 54, United States Code;
(v)
the Endangered Species Act of 1973 ( 16 U.S.C. 1531 et seq. );
(vi)
division A of subtitle III of title 54, United States Code (commonly referred to as the ‘National Historic Preservation Act’); or
(vii)
section 4 of the Act of July 23, 1955 (commonly known as the  Surface Resources Act of 1955 ) (69 Stat. 368, chapter 375;  30 U.S.C. 612 );
(E)
restores any right (including a right of entry, use, or occupancy, or right to conduct operations) of a claimant that—
(i)
existed prior to the date on which the land was closed to, or withdrawn from, location under the general mining laws; and
(ii)
has been extinguished by such closure or withdrawal; or
(F)
modifies section 404 of division E of the Consolidated Appropriations Act, 2024 ( Public Law 118–42 ; 138 Stat. 284).
 .
(b)
Abandoned Hardrock Mine Fund
(1)
Establishment
There is established in the Treasury of the United States a separate account, to be known as the  Abandoned Hardrock Mine Fund  (referred to in this subsection as the  Fund ).
(2)
Source of deposits
Any amounts collected by the Secretary of the Interior pursuant to the claim maintenance fee under section 10101(a)(1) of the Omnibus Budget Reconciliation Act of 1993 ( 30 U.S.C. 28f(a)(1) ) on mill sites located under subsection (c) of section 2337 of the Revised Statutes ( 30 U.S.C. 42 ) shall be deposited into the Fund.
(3)
Use
The Secretary of the Interior may make expenditures from amounts available in the Fund, without further appropriation, only to carry out section 40704 of the Infrastructure Investment and Jobs Act ( 30 U.S.C. 1245 ).
(4)
Allocation of funds
Amounts made available under paragraph (3)—
(A)
shall be allocated in accordance with section 40704(e)(1) of the Infrastructure Investment and Jobs Act ( 30 U.S.C. 1245(e)(1) ); and
(B)
may be transferred in accordance with section 40704(e)(2) of that Act ( 30 U.S.C. 1245(e)(2) ).
(c)
Clerical amendments
Section 10101 of the Omnibus Budget Reconciliation Act of 1993 ( 30 U.S.C. 28f ) is amended—
(1)
by striking  the Mining Law of 1872 ( 30 U.S.C. 28–28e )  each place it appears and inserting  sections 2319 through 2344 of the Revised Statutes ( 30 U.S.C. 22 et seq. ) ;
(2)
in subsection (a)—
(A)
in paragraph (1)—
(i)
in the second sentence, by striking  Such claim maintenance fee  and inserting the following:
(B)
Fee
The claim maintenance fee under subparagraph (A)
 ; and
(ii)
in the first sentence, by striking  The holder of  and inserting the following:
(A)
In general
The holder of
 ; and
(B)
in paragraph (2)—
(i)
in the second sentence—
(I)
by striking  the Mining Law of 1872 (30 U.S.C. 28 to 28e)  and inserting  sections 2319 through 2344 of the Revised Statutes ( 30 U.S.C. 22 et seq. ) ; and
(II)
by striking  Such claim maintenance fee  and inserting the following:
(B)
Fee
The claim maintenance fee under subparagraph (A)
 ; and
(ii)
in the first sentence, by striking  The holder of  and inserting the following:
(A)
In general
The holder of
 ; and
(3)
in subsection (b)—
(A)
in the second sentence, by striking  The location fee  and inserting the following:
(2)
Fee
The location fee
 ; and
(B)
in the first sentence, by striking  The claim main tenance fee  and inserting the following:
(1)
In general
The claim maintenance fee
 .
III
Geothermal energy advancement
301.
Effect of pending civil actions on processing applications relating to geothermal leasing
Section 4 of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1003 ) is amended by adding at the end the following:
(h)
Effect of pending civil actions on processing applications relating to geothermal leasing
(1)
Definition of authorization
In this subsection, the term  authorization  means any license, permit, approval, finding, determination, or other administrative decision issued by a Federal agency, or any interagency consultation, that is required or authorized under Federal law (including regulations) in order to site, construct, reconstruct, or commence operation of a geothermal project administered by a Federal agency.
(2)
Requirement to process applications
Notwithstanding any pending civil action that affects an application for a geothermal drilling permit, sundry notice, notice to proceed, right-of-way, or any other authorization under a valid existing geothermal lease, the Secretary shall, unless a Federal court vacates or provides injunctive relief for the applicable geothermal lease, geothermal drilling permit, sundry notice, notice to proceed, right-of-way, or other authorization, approve and issue, or deny, each such application not later than 60 days after completing all requirements under applicable Federal laws (including regulations), including the National Environmental Policy Act of 1969 ( 42 U.S.C. 4321 et seq. ), the Endangered Species Act of 1973 ( 16 U.S.C. 1531 et seq. ), and division A of subtitle III of title 54, United States Code.
(3)
No new authority for Federal courts
Nothing in this subsection modifies any existing authority of a Federal court to vacate or provide injunctive relief for a geothermal lease, geothermal drilling permit, sundry notice, notice to proceed, right-of-way, or other authorization.
 .
302.
Cost recovery from geothermal leasing, permitting, and inspections
(a)
In general
Section 6 of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1005 ) is amended by adding at the end the following:
(j)
Cost recovery
(1)
In general
During the period beginning on the date of enactment of the  FREEDOM Act  and ending on September 30, 2033, the Secretary may require an applicant for, or holder of, a geothermal lease to reimburse the United States for all reasonable administrative and other costs incurred by the United States from—
(A)
processing the application for the geothermal lease, including any application for an operations plan, geothermal drilling permit, utilization plan, site license, facility construction permit, commercial use permit, and any other approval associated with a geothermal lease; and
(B)
inspecting and monitoring—
(i)
geophysical exploration activities;
(ii)
the drilling, plugging, or abandonment of wells; and
(iii)
the construction, operation, termination, or reclamation of any well site or facility for the utilization of geothermal resources pursuant to the geothermal lease.
(2)
Factor for consideration
In determining whether to require reimbursement under paragraph (1), the Secretary shall take into consideration whether there is in effect a cooperative cost-share agreement between the United States and the holder of a geothermal lease.
(3)
Adjustments
The Secretary may reduce the amount required to be reimbursed under paragraph (1) if the Secretary determines that—
(A)
full reimbursement would impose on the applicant an economic hardship; or
(B)
a less-than-full reimbursement is necessary to promote the greatest use of geothermal resources.
(4)
Use
The amounts reimbursed under this subsection shall be—
(A)
credited to the currently applicable appropriation, account, or fund of the Department of the Interior as discretionary offsetting collections; and
(B)
available only to the extent provided in advance in appropriations Acts for—
(i)
processing applications for geothermal leases, including any applications for operations plans, geothermal drilling permits, utilization plans, site licenses, facility construction permits, commercial use permits, and any other approval associated with geothermal leases; and
(ii)
inspecting and monitoring—
(I)
geophysical exploration activities;
(II)
the drilling, plugging, or abandonment of wells; and
(III)
the construction, operation, termination, or reclamation of any well site or facility for the utilization of geothermal resources pursuant to geothermal leases.
 .
(b)
Report
(1)
In general
Not later than 5 years after the date of enactment of this Act, the Secretary of the Interior, in consultation with representatives of the geothermal industry and other stakeholders, shall submit to the Committee on Energy and Natural Resources of the Senate and the Committee on Natural Resources of the House of Representatives, and make publicly available on the website of the Department of the Interior, a report that includes—
(A)
an assessment of how the amendment made by subsection (a) affected the geothermal program of the Bureau of Land Management during the preceding 5 years;
(B)
any recommendations for reauthorization of subsection (j) of section 6 of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1005 ) (as added by subsection (a)); and
(C)
any other recommendations for updates to—
(i)
subsection (j) of section 6 of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1005 ) (as so added); or
(ii)
the geothermal program of the Bureau of Land Management.
(2)
Information
In developing the report under paragraph (1), the Secretary of the Interior shall solicit information from representatives of the geothermal industry and other stakeholders.
303.
Publication of Gold Book for geothermal operations on Federal land
(a)
Identification
Not later than 1 year after the date of enactment of this Act, the Secretary of the Interior, in consultation with other relevant Federal agencies, shall identify standard procedures and guidelines for efficient and environmentally responsible geothermal leasing and permitting to the extent such standard procedures and guidelines are not addressed in the fourth edition of the document of the Bureau of Land Management entitled  Surface Operating Standards and Guidelines for Oil and Gas Exploration and Development , commonly known as the  Gold Book , and most recently revised in 2007.
(b)
Publication
(1)
In general
Not later than 270 days after identifying standard procedures and guidelines under subsection (a), the Secretary of the Interior shall publish an updated version of the Gold Book, incorporating any changes necessary to support efficient and environmentally responsible geothermal leasing and permitting, for use by the field offices of the Bureau of Land Management and geothermal operators.
(2)
Renaming
The Secretary of the Interior shall rename the Gold Book as the Secretary determines to be appropriate to reflect the incorporation of standard procedures and guidelines relating to geothermal development.
(c)
Consultation
Before publishing an updated version of the Gold Book under subsection (b)(1), the Secretary of the Interior shall consult with—
(1)
other relevant Federal agencies, including field offices of the Bureau of Land Management; and
(2)
outside stakeholders, including developers and other experts.
(d)
Periodic revision
The Secretary of the Interior shall—
(1)
not less frequently than once every 5 years, review the most recent version of the Gold Book (or a successor to that book); and
(2)
as the Secretary of the Interior determines to be necessary to support efficient and environmentally responsible geothermal leasing and permitting, publish an updated version of the Gold Book (or a successor).
(e)
Inclusions
Each updated version of the Gold Book (or a successor to that book) shall include standard procedures and guidelines for ensuring the efficient review and approval of environmentally responsible geothermal development, including—
(1)
exploration and geophysical operations;
(2)
permitting lease operations;
(3)
compliance with all applicable laws (including regulations);
(4)
construction and maintenance; and
(5)
drilling, production, and utilization operations.
304.
Geothermal Ombudsman and Permitting Task Force
(a)
Definitions
In this section:
(1)
Bureau
The term  Bureau  means the Bureau of Land Management.
(2)
Geothermal authorization
The term  geothermal authorization  means any license, permit, approval, finding, determination, or other administrative decision issued by the Bureau (including any interagency consultation) that is required or authorized under Federal law in order to site, construct, reconstruct, or commence operation of a project that—
(A)
is located in whole or in part on land subject to geothermal leasing under section 3 of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1002 ); and
(B)
uses geothermal energy to generate heat or electricity.
(3)
Geothermal Ombudsman
The term  Geothermal Ombudsman  means the Geothermal Ombudsman appointed under subsection (b)(1).
(4)
Task Force
The term  Task Force  means the Geothermal Permitting Task Force established under subsection (c)(1).
(b)
Geothermal Ombudsman
(1)
In general
Not later than 60 days after the date of enactment of this Act, the Secretary of the Interior shall appoint from within the Bureau an individual to serve as Geothermal Ombudsman.
(2)
Duties
The Geothermal Ombudsman shall—
(A)
act as a liaison between—
(i)
the individual field, district, and State offices of the Bureau;
(ii)
the Division Chief of the National Renewable Energy Coordination Office of the Bureau; and
(iii)
the Director of the Bureau;
(B)
provide dispute resolution services for disputes between the individual field, district, and State offices of the Bureau and applicants for geothermal authorizations;
(C)
monitor and facilitate permit processing practices and timelines across individual field offices of the Bureau;
(D)
develop best practices for the permitting and leasing process for geothermal resources; and
(E)
coordinate with the Federal Permitting Improvement Steering Council.
(c)
Geothermal Permitting Task Force
(1)
Establishment
Not later than 60 days after the date of enactment of this Act, the Secretary of the Interior shall establish within the Bureau a task force, to be known as the  Geothermal Permitting Task Force .
(2)
Leadership
The Task Force shall be headed by the Geothermal Ombudsman.
(3)
Permitting support
The Task Force shall support the duties of the Geothermal Ombudsman under subsection (b).
(4)
Cross-office personnel assignments
(A)
In general
The Geothermal Ombudsman, acting as head of the Task Force, may coordinate with any bureau or office of the Department of the Interior to assign personnel with relevant expertise to assist with the completion of geothermal authorizations in Bureau field, district, or State offices other than the official duty stations at which such personnel are located if—
(i)
the applicable bureau or office determines that such an assignment will not materially delay ongoing completion of geothermal authorizations within the applicable official duty station; and
(ii)
approval is received from the head of that official duty station.
(B)
Assigned personnel requirements
An employee assigned to assist with the completion of geothermal authorizations pursuant to subparagraph (A) shall—
(i)
work in-person full-time at an official office of the Department of the Interior;
(ii)
as the Geothermal Ombudsman determines to be necessary, travel to the Bureau field, district, or State office with jurisdiction over the geothermal authorizations to which the employee has been assigned;
(iii)
participate as part of the team of personnel working on geothermal authorizations to which the employee has been assigned; and
(iv)
regularly report to the head of the Bureau field, district, or State office with jurisdiction over the geothermal authorizations to which the employee has been assigned.
(C)
Retention allowances
(i)
In general
Subject to the availability of appropriations, the Geothermal Ombudsman may pay a retention allowance to an employee assigned to assist with the completion of geothermal authorizations under subparagraph (A).
(ii)
Requirements
A retention allowance under clause (i)—
(I)
shall be stated as the percentage of the rate of basic pay of the applicable employee, subject to the condition that such an allowance may not exceed 25 percent of that rate of basic pay;
(II)
may not be considered to be part of the basic pay of the employee;
(III)
may not be appealed on reduction or elimination; and
(IV)
shall be paid at the same time and in the same manner as the basic pay of the employee is paid.
(iii)
Factors for consideration
In paying a retention allowance under clause (i), the Geothermal Ombudsman shall take into consideration—
(I)
any specialized expertise of the applicable employee relating to geothermal authorizations;
(II)
the demonstrated need to retain an employee to meet the performance improvement objectives for geothermal authorization timelines and develop best practices for completion of geothermal authorizations; and
(III)
the difficulty in recruiting or replacing qualified personnel with relevant expertise relating to geothermal authorizations.
(D)
Savings clause
The assignment of personnel pursuant to this paragraph shall not alter the underlying jurisdiction of any office of the Bureau with respect to geothermal authorizations.
(d)
Report
The Geothermal Ombudsman shall submit to the Committee on Energy and Natural Resources of the Senate and the Committee on Natural Resources of the House of Representatives an annual report that—
(1)
describes the activities of the Task Force during the preceding year; and
(2)
evaluates the effectiveness of geothermal authorization processing during the preceding year.
305.
Geothermal royalties
(a)
Definitions
(1)
In general
Section 2 of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1001 ) is amended—
(A)
by striking the section designation and heading and all that follows through  the term—  in the matter preceding subsection (a) and inserting the following:
2.
Definitions
In this Act:
 ;
(B)
in each of subsections (a) through (d), by striking the semicolon at the end and inserting a period;
(C)
in subsection (c), by striking  resources  and inserting  resource ;
(D)
by striking subsection (e);
(E)
in subsection (f)—
(i)
in paragraph (1), by striking  Section  and inserting  section ;
(ii)
by redesignating paragraphs (1) through (4) as subparagraphs (A) through (D), respectively, and indenting appropriately; and
(iii)
by striking the subsection designation and all that follows through  limited to,  in the matter preceding subparagraph (A) (as so redesignated) and inserting the following:
(f)
 significant thermal feature within a unit of the National Park System  includes
 ;
(F)
in subsection (g), by striking  ; and  at the end and inserting a period;
(G)
by redesignating subsections (a), (b), (c), (d), (f), and (g) as paragraphs (7), (4), (5), (1), (8), and (2), respectively, indenting the paragraphs appropriately, and moving the paragraphs so as to appear in numerical order;
(H)
in each of paragraphs (1), (2), (4), (5), (7), and (8) (as so redesignated)—
(i)
by inserting  The term  after the paragraph designation; and
(ii)
by adding a paragraph heading, the text of which comprises the term defined in the paragraph;
(I)
by inserting after paragraph (2) (as so redesignated) the following:
(3)
Geothermal electric generating facility
(A)
In general
The term  geothermal electric generating facility  means a facility, including all necessary equipment and structures (including turbines and cooling equipment), that produces electricity using geothermal resources.
(B)
Treatment
For purposes of section 5(a)(1), a facility described in subparagraph (A) shall be considered to be a separate facility from any other such facility unless the facility shares a turbine with the other facility.
 ; and
(J)
by inserting after paragraph (5) (as so redesignated) the following:
(6)
In-service date
The term  in-service date , with respect to a geothermal electric generating facility, means the date on which the geothermal electric generating facility commences operation.
 .
(2)
Conforming amendments
(A)
Section 6(i) of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1005(i) ) is amended by striking  as defined in section 2(c) herein .
(B)
Section 28(a)(1) of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1026(a)(1) ) is amended, in the matter preceding subparagraph (A), by striking  , as defined in section 2(f), .
(b)
Royalties on electricity produced using geothermal resources
Section 5(a) of the Geothermal Steam Act of 1970 ( 30 U.S.C. 1004(a) ) is amended by striking paragraph (1) and inserting the following:
(1)
a royalty on electricity produced using geothermal resources, other than direct use of geothermal resources, in an amount equal to, with respect to a geothermal electric generating facility producing electricity from geothermal resources—
(A)
not less than 1 percent, and not more than 2.5 percent, of the gross proceeds from the sale of electricity produced by the geothermal electric generating facility from those geothermal resources during each year of the 10-year period beginning on the in-service date of the geothermal electric generating facility; and
(B)
not less than 2 percent, and not more than 5 percent, of the gross proceeds from the sale of electricity produced by the geothermal electric generating facility from those geothermal resources during each year after the 10-year period described in subparagraph (A);
 .
306.
NEPA review
Section 390 of the Energy Policy Act of 2005 ( 42 U.S.C. 15942 ) is amended—
(1)
in subsection (a)—
(A)
by striking  (NEPA)  and inserting  ( 42 U.S.C. 4321 et seq. ) (referred to in this section as  NEPA ) ;
(B)
by inserting  ( 30 U.S.C. 181 et seq. )  after  Mineral Leasing Act ; and
(C)
by inserting  or the Geothermal Steam Act of 1970 ( 30 U.S.C. 1001 et seq. ) for the purpose of exploration or development of geothermal resources  before the period at the end; and
(2)
in subsection (b)—
(A)
in paragraph (2), by striking  oil or gas  and inserting  oil, gas, or geothermal resources ; and
(B)
in paragraph (3), by striking  oil or gas  and inserting  oil, gas, or geothermal resources .